Ohio Revised Code Search

...des any lessee, receiver, corporation, company, or persons owning, operating, or managing any railroad with whom or in whose behalf contracts as provided in such sections are made.

...Any person, association of persons, or corporation contracting for the construction of a railroad, depot buildings, water tanks, or any part thereof, shall pay to each person performing labor or furnishing materials stipulated for in the contract with the owner of the railroad, under a contract express or implied with the original contractor, or with any subcontractor, for the whole or any part of the work stipulated...

...its road, or any part thereof, that payments thereunder shall be made in the following order of priority: (A) To the persons performing labor, furnishing materials or boarding, on the order of any contractor or subcontractor to persons employed by them, or either of them, in furnishing materials or labor for or in the construction of such railroad, without preference. (B) To any subcontractor, any balance due under...

...brought to enforce the lien within that time, it continues in force until finally adjudicated.

...ial furnished, or labor performed, the time when the contractor or subcontractor for whom, and the section and place where, on the line of the road the labor was performed, or material furnished, and the amount due therefor, after deducting all payments and setoffs. In case of boarding, such affidavit must have attached thereto an itemized account thereof, showing the name of the contractor or subcontractor on ...

...davit, and serve such notice within the time prescribed, has waived all claim under this section and sections 1311.41 and 1311.42 of the Revised Code, against the railroad company.

...A person obtaining and holding a lien as provided for in sections 1311.41 to 1311.43, inclusive, of the Revised Code, in addition to his remedies under sections 1311.38 to 1311.47, inclusive, of the Revised Code may proceed by petition as in other cases of lien, against the owner of and all other persons interested, as lienholders or otherwise, in such a railroad, and obtain such judgment as justice and equity requi...

...led, it may be given by publication in some newspaper of general circulation therein, for the period of two weeks. If such contractor or subcontractor disputes any of the claims, the company or owner of the road shall withhold payment of those in dispute until they are adjusted.

...ion, the claimant, in such case, shall commence an action on his claim before the proper tribunal, within forty days after notice that it has been disputed, and prosecute it to final judgment without delay. The amount thus ascertained or adjudicated shall then be paid by the railroad owner. After notice given as provided in section 1311.45 of the Revised Code, if no objection is filed against such claim within ten d...

...ess of the actual construction contract price of the railroad company.

... contract with the owner shall have a lien on such animal to secure payment for food and board furnished.

...such owner. If the animal is sold for a price which exceeds the amount of the lien, plus costs incurred by the lienholder, the remaining balance shall be paid by the lienholder to the owner or to such other person as may be legally entitled to receive same. If the lienholder sells or otherwise disposes of any animal without first giving the notice required by this section he shall not pursue any deficiency upon such ...

..., or registered pure-bred bull, has a lien upon its get for the period of twelve months after birth thereof, for the payment of the service of such stallion, jack, or bull.

...lic sale after two weeks' notice of the time and place of sale by notices posted in five conspicuous and public places in the township or municipal corporation where proceedings in replevin are had. Out of the proceeds of sale such keeper or owner may retain the amount due him for such service, with the costs by him incurred in the replevin suit. He must account to the owner of the get for any surplus realized b...

...or when there is no agreed price at the time of delivery, the value of the agricultural product as determined by the "market news service" of the Ohio department of agriculture on the date the agricultural producer or handler files the affidavit permitted under section 1311.56 of the Revised Code. (D) Any waiver by a producer or handler of the producer's or handler's right to an agricultural product lien is voi...

...er. If there was no agreed price at the time of delivery or first delivery, the lien claimant shall include in the affidavit the pricing method which the lien claimant and handler agreed to utilize in their contract to determine the amount owed the lien claimant. In such cases, and for informational purposes only, the lien claimant shall include in the affidavit an estimate of the amount owed the lien claimant by the...

...cured creditor receives full payment from the agricultural product handler; (2) At the option of the lienholder or the lienholder's secured creditor, less than full payment is received pursuant to a written agreement with the handler; (3) A final judgment is entered by a court having jurisdiction in an action adjudicating the status of the agricultural product lien. (C) Notwithstanding division (B) of this se...

... owners, part owners, and lessees would enjoy and be subject to, if alive.

...sed Code and includes any part or equipment of the aircraft. "Aircraft" includes an abandoned aircraft, unless otherwise specified. (B) "Abandoned aircraft" means an aircraft to which both of the following apply: (1) It is located on the premises of a public-use airport. (2) The owner or operator has not paid any tie-down, hangar, rent, or storage costs for use of the premises for at least ninety consecutive da...

...ishes materials for an aircraft has a lien upon the aircraft to secure payment for the labor, storage, and materials. Except as provided in division (B) of this section, any person who owns or operates an airport or repair shop and whose employee performs labor upon, stores, or furnishes materials for an aircraft has a lien upon the aircraft to secure payment for the labor, storage, and materials. (B) Unless the ai...

...oes not remove the abandoned aircraft from the airport and pay all accrued fees and charges. (2) The notice described in division (B)(1) of this section may be sent by any of the following methods: (a) Certified or express mail with return receipt requested; (b) Certified mail with electronic tracking; (c) A commercial carrier service utilizing any form of delivery requiring a signed receipt; (d) Personal s...

...is in possession of the aircraft at the time of filing; (2) Ninety days after the date on which the lien claimant or the lien claimant's employee surrendered possession of the aircraft that is subject to the lien; (3) Ninety days after the date by which the owner of an abandoned aircraft that is subject to the lien was required to remove the aircraft from the lien claimant's property in accordance with section 13...

...validate the lien if the lien claimant complies with division (A) of this section.

...(A) A lien claimant who perfects a lien in accordance with section 1311.73 of the Revised Code has priority over all other liens, claims, or encumbrances, except wage and salary claims of workers who have no ownership interests in the business of the lien claimant and amounts that are owed by the lien claimant to the aircraft owner and that are subject to setoff against the amounts due for the labor, storage, and mat...

...(A) A lien claimant may enforce a lien that arises under section 1311.72 of the Revised Code by bringing an action to recover the monetary amount secured by the lien in a court having jurisdiction in the county in which either of the following occurred: (1) The storage took place, the labor that is the basis of the lien was performed, or the materials that are the basis of the lien were furnished; (2) The county ...