Ohio Revised Code Search

...or any part thereof, that payments thereunder shall be made in the following order of priority: (A) To the persons performing labor, furnishing materials or boarding, on the order of any contractor or subcontractor to persons employed by them, or either of them, in furnishing materials or labor for or in the construction of such railroad, without preference. (B) To any subcontractor, any balance due under his contr...

...nd 1311.40 of the Revised Code, has a lien for its payment upon such railroad. Such lien has precedence over any lien taken, or to be taken, and subsists for one year from the date of filing the attested account provided for in section 1311.42 of the Revised Code. If an action is brought to enforce the lien within that time, it continues in force until finally adjudicated.

...for the railroad, shall file with the county recorder of the county where the labor was performed, or material or boarding furnished, an affidavit containing an itemized statement of the kind and amount of material furnished, or labor performed, the time when the contractor or subcontractor for whom, and the section and place where, on the line of the road the labor was performed, or material furnished, and the...

... the railroad company, by delivering or leaving a copy thereof at his usual place of residence or place of doing business. Such notice shall contain a statement of the facts of his filing such affidavit, the county wherein filed, the amount of his claim, whether for labor, materials, or boarding furnished, and the contractor or subcontractor for whom rendered. When the notice cannot be served in the county where the ...

...ised Code, in addition to his remedies under sections 1311.38 to 1311.47, inclusive, of the Revised Code may proceed by petition as in other cases of lien, against the owner of and all other persons interested, as lienholders or otherwise, in such a railroad, and obtain such judgment as justice and equity require. For the purposes of such suit any number of such lienholders may join as parties plaintiff by separatel...

...labor, boarding, or materials furnished under a contract with him will be paid, which notice may be served upon him personally or upon his authorized agent or foreman, by the owner of the railroad, or any officer or agent thereof, stating therein the time of their payment. On request of such contractor or subcontractor he shall be permitted to examine such lien claims before they are paid at any time after the notic...

...If any claim is disputed and is not settled or submitted to arbitration, the claimant, in such case, shall commence an action on his claim before the proper tribunal, within forty days after notice that it has been disputed, and prosecute it to final judgment without delay. The amount thus ascertained or adjudicated shall then be paid by the railroad owner. After notice given as provided in section 1311.45 of the Re...

...n construction of such railroad. The amount of such claim shall not exceed the wages of the person performing labor or furnishing materials, to whom furnished, or the amount found due such contractor, or subcontractor, under sections 1311.38 to 1311.47, inclusive, of the Revised Code. In every such case the requirements, as to filing affidavits and giving notices must be strictly complied with, and the aggregate of a...

... contract with the owner shall have a lien on such animal to secure payment for food and board furnished.

...nholder may sell the animal at public sale to satisfy such lien, provided that before the animal is offered for sale the lienholder shall give ten days' notice of the time and place of sale in a newspaper of general circulation in the county where food or board was furnished. The lienholder, on the day following publication, shall mail a copy of the public notice to the owner by registered mail at the last known addr...

..., or registered pure-bred bull, has a lien upon its get for the period of twelve months after birth thereof, for the payment of the service of such stallion, jack, or bull.

...y replevin of the property before any county or municipal court having territorial jurisdiction where it is found. Upon gaining possession thereof, on first giving ten days' notice to the reputed owner of his intention to do so, he may sell it at public sale after two weeks' notice of the time and place of sale by notices posted in five conspicuous and public places in the township or municipal corporation where proc...

...) "Agricultural product handling" means engaging in or participating in the business of buying, selling, exchanging, or negotiating or soliciting a purchase, sale, resale, exchange, or transfer of an agricultural product. (3) "Agricultural product handler" or "handler" means any person who is engaged in the business of agricultural product handling, except that a person who sells only those agricultural produc...

...en by recording, in the office of the county recorder in the county where the agricultural product was delivered to the agricultural product handler, an affidavit that includes the date of delivery, or first delivery if there was a series of deliveries under the contract, the name of the agricultural product handler to whom the agricultural product was delivered, and the amount owed the lien claimant by the handler. ...

...ect to setoff, and except that secured creditors who have security interests under Chapter 1309. of the Revised Code have priority over liens perfected by agricultural handlers pursuant to section 1311.56 of the Revised Code. If several liens are obtained by several persons on the same agricultural product, the person who perfects such a lien first has priority over all other agricultural product lienholders. ...

... owners, part owners, and lessees would enjoy and be subject to, if alive.

...raft" includes an abandoned aircraft, unless otherwise specified. (B) "Abandoned aircraft" means an aircraft to which both of the following apply: (1) It is located on the premises of a public-use airport. (2) The owner or operator has not paid any tie-down, hangar, rent, or storage costs for use of the premises for at least ninety consecutive days. (C) "Director" means the director or other chief executive o...

... labor, storage, and materials. (B) Unless the aircraft is an abandoned aircraft, no person shall have a lien pursuant to division (A) of this section if the person has possession of the aircraft or if the cost of the storage, the labor performed, or the materials furnished for the aircraft is greater than or equal to one thousand dollars and the owner of the aircraft has not requested or consented to the performan...

...of the Revised Code if, within thirty calendar days after the date of receipt of such notice or notification that delivery was not possible, the owner does not remove the abandoned aircraft from the airport and pay all accrued fees and charges. (2) The notice described in division (B)(1) of this section may be sent by any of the following methods: (a) Certified or express mail with return receipt requested; (b)...

...rson claiming the lien shall make and file for record with the United States federal aviation administration an affidavit verified under oath that includes all of the following information: (a) The amount owed to the lien claimant for the labor, storage, or materials; (b) A description of the aircraft that reasonably identifies it including the manufacturer, model, serial number, and registration number of the ai...

...ays after filing the affidavit with the United States federal aviation administration. The lien claimant shall mail the copy of the affidavit by certified mail, or if the copy of the affidavit is returned as unclaimed, then by ordinary mail, to the address of the owner of the aircraft as last recorded with the United States federal aviation administration. (B) Failure of the owner to receive a copy of the affidavit ...

...he business of the lien claimant and amounts that are owed by the lien claimant to the aircraft owner and that are subject to setoff against the amounts due for the labor, storage, and materials that are the basis for the lien. (B) If more than one lien is perfected by more than one lien claimant in accordance with section 1311.73 of the Revised Code on the same aircraft, liens shall be ranked in priority in the or...

... years after the date an affidavit is filed pursuant to section 1311.73 of the Revised Code, or until one of the following occurs within that six-year period: (1) The lien claimant receives full payment of the amount due the lien claimant as stated in the affidavit filed pursuant to section 1311.73 of the Revised Code or in the judgment or order granted pursuant to this section by a court having jurisdiction; (2)...

...th a court having jurisdiction in the county in which the labor that is the basis of the lien was performed, in which the aircraft was stored, or in which the materials that are the basis of the lien were furnished, a bond, payable to the lien claimant, for the full amount owed to the lien claimant as stated in an affidavit filed pursuant to section 1311.73 of the Revised Code for the labor or materials, and conditio...

...it. Service of the notice is deemed completed when a return receipt is received by the owner indicating delivery of the notice. If a return receipt shows a failure or refusal of delivery, service is deemed completed after the owner mails a second copy of the notice by ordinary mail, provided that the notice is not returned by the postal authorities within fourteen days after the date of mailing with an endorsement sh...