Ohio Revised Code Search

...common pleas, on the application of the board of directors of the sanitary district or on the application of any holder of any bonds which have been issued pursuant to such sections, shall promptly and without delay remedy all defects or irregularities as the case requires by directing the board of appraisers of the sanitary district to make, in the manner provided in section 6115.30 of the Revised Code, a new apprai...

...t. Thereupon the court shall direct the board of appraisers of the sanitary district to make such readjustment of appraisal in the manner provided in sections 6115.01 to 6115.79, inclusive, of the Revised Code, and said board shall make its report. The same proceedings shall be had thereon, as nearly as may be, as are provided in such sections for the appraisal of benefits accruing for original construction. In makin...

...strict are located shall execute to the board of directors of the sanitary district a bond with at least two good and sufficient sureties or a surety company, which bond shall be paid for by the district, in a sum not less than the probable amount of any annual levy of the assessment to be collected by him during any one year, conditioned that said treasurer shall pay over and account for all assessments so collecte...

...de may be enforced at the option of the board of directors of the sanitary district by an action on delinquent tax bills or assessment bills, made and certified by the county auditor, which action shall be instituted in the court of common pleas, without regard to the amount of the claim, within six months after the thirty-first day of December of the year for which said assessments were levied. The suit shall be bro...

...f the court accepting the report of the board of appraisers, and upon receipt of a copy, certified by the secretary of the sanitary district, of the resolution of the board of directors levying the assessment, shall receive and file the order, and immediately take all the legal and necessary steps to collect the same. The governing or taxing body shall levy an assessment, by a uniform rate upon all the taxable prope...

...The board of directors of a sanitary district may police the works of the district, and in times of great emergency may compel assistance in the protection of such works. The board may prevent persons, vehicles, or livestock from passing over the works of the district in any manner which would result in damage thereto.

...or want of legal notice, or in case the board of directors of the sanitary district determines that any notice with reference to any land is faulty, then the board may file a motion in the original cause asking that the court order notice to be given to the owner of such land and set a time for hearing as provided in such sections. If the original notice as a whole was sufficient and was faulty only with reference to...

... of the Revised Code, the action of the board of county commissioners shall be final, and the board may proceed to issue or incur public obligations and construct the improvement. If, at the end of that ten days, any owner of property to be assessed for the improvement has effected an appeal, the construction of the improvement shall be deferred until the matters appealed from have been disposed of in court.

...from the final order or judgment of the board upon any of the questions mentioned in such section, shall on or before the date of the passage of the improvement resolution give notice in writing of an intention to appeal, specifying therein the matters to be appealed from. The board shall fix the amount of the bond to be given by the appellant, which amount shall be reasonable, and shall make an entry thereof upon it...

...rs from the transcript certified to the board of county commissioners by the probate judge that the boundaries of the assessment district should be changed or that the tentative assessment should be modified, the board may make such changes or modifications and proceed with the improvement, provided that the necessity of such improvement has not been denied by the probate court or the cost thereof found to exceed the...

...n any record required to be kept by any board or officer, and without finding error the court may correct any gross injustice in the assessment made by the board of county commissioners. The court on the final hearing shall make such order as it deems equitable, and order any tax or assessment levied against the plaintiff to remain on the duplicate for collection, or order it to be levied in whole or in part, or perp...

...Whenever in the opinion of the board of county commissioners it becomes necessary to construct a sewer within the boundaries of a municipal corporation for the service of sewer districts wholly outside of such municipal corporation, the board may construct such sewer in the streets and alleys of such municipal corporation but shall restore all such streets and alleys to their original condition, and the cost thereof ...

... in a county for sanitary purposes, the board of county commissioners of such county may make surveys thereof and prepare plans and specifications thereof. Upon approval by the director of such plans and specifications, the board may construct and maintain said trunk or main sewer or part thereof within or without the limits of a municipal corporation, regulate the tapping thereof by lateral sewers, and prescribe the...

...The board of county commissioners may acquire by purchase or appropriation proceedings all real and personal property necessary for the proper construction and maintenance of a trunk or main sewer provided for in section 6117.46 of the Revised Code. The board may occupy any public road, street, avenue, or alley for such trunk or main sewer or part thereof.

... regional water and sewer district, the board of trustees thereof may submit to the electors within the territorial limits of the district the question of issuing bonds of such district and also the necessity of the levy of a tax outside the limitation imposed by Section 2 of Article XII, Ohio Constitution, to pay the interest on and to retire the bonds. Such bonds when so approved by the electors may be issued to pa...

...ection 6119.31 of the Revised Code, the board of trustees of a regional water and sewer district may provide a system of sanitary and/or storm water sewerage, herein referred to only as sewerage, for any part of the area included within the district. Such a plan shall be devised with regard to the present and prospective needs and interests of the area, and shall be confirmed by the board.

...When the board of trustees of a regional water and sewer district deems it necessary to construct all or a part of the sewers provided for in the plan devised in accordance with section 6119.19 of the Revised Code, the board shall declare by resolution the necessity thereof. Such resolution shall contain a declaration of the necessity of such improvement, a statement of the districts, areas, or parts thereof pr...

...ection 6119.25 of the Revised Code, the board of trustees of the regional water and sewer district shall determine whether it will proceed with the proposed improvement or not. If the board decides to proceed with the improvement a resolution for that purpose shall be passed. Such resolution shall contain a statement naming the districts or parts thereof proposed to be constructed, the character of the material to be...

...If it deems it expedient, the board of trustees of the regional water and sewer district may assess the real estate as provided in the resolution to improve and collect such assessments, or may issue bonds in anticipation of the collection of such assessments before the work is done or contracted for. The board may delay such assessment until the work is completed and upon the filing of a certificate showing the comp...

...If in its opinion it is expedient, the board of trustees of a regional water and sewer district may provide for the construction of main sewers and drains and branch sewers and drains connecting therewith without previously adopting any plan of sewerage or division of the area or any part thereof into districts, and may assess the cost and expense of such construction upon such lots and lands as are designated in the...

... Chapter 6119. of the Revised Code. The board of trustees of such district may assess upon abutting, adjacent, contiguous, or other specially benefited lots or lands in the district all or any part of the cost connected with the improvement of any street, alley, or public road or place, or a property or easement of the district by constructing any water resource project or part thereof which the board declares conduc...

...vate corporations, public corporations, boards of township trustees, boards of education of school districts, the mayor or legislative authority of a municipal corporation, the director of any department, office, or institution of the state, and the trustees of any state, county, or municipal public institution. "Owner" also includes any public corporation and the director of any department, office, or institution of...

...When the board of county commissioners, at a regular or called session, upon the filing of a petition as provided in sections 6131.01 to 6131.64 of the Revised Code, finds that the granting of the petition and the construction of an improvement is necessary for disposal or removal of surplus water, for controlled drainage of any land, for irrigation, for storage of water to regulate stream flow or to prevent the over...

...file an amendment with the clerk of the board of county commissioners not more than twenty-one days after the view required by section 6131.07 of the Revised Code and shall include the information required by section 6131.04 of the Revised Code along with the amendment. (C) If the petition was filed by the county under division (D) of section 6131.04 of the Revised Code, any proposed amendment to the petition shall...

...cause dismissed. (C) The clerk of the board of county commissioners shall release the bond at the expiration of the thirty-day appeal period provided for in section 6131.25 of the Revised Code after an order to proceed with the project by the board at the first hearing or at the termination of the appeal.