Ohio Revised Code Search

...lroad with whom or in whose behalf contracts as provided in such sections are made.

...ciation of persons, or corporation contracting for the construction of a railroad, depot buildings, water tanks, or any part thereof, shall pay to each person performing labor or furnishing materials stipulated for in the contract with the owner of the railroad, under a contract express or implied with the original contractor, or with any subcontractor, for the whole or any part of the work stipulated in the original...

...road company shall provide, in its contract with any person, association of persons, or corporation for the construction of its road, or any part thereof, that payments thereunder shall be made in the following order of priority: (A) To the persons performing labor, furnishing materials or boarding, on the order of any contractor or subcontractor to persons employed by them, or either of them, in furnishing material...

...ishes boarding on the order of any contractor or subcontractor, to persons employed by them or either of them, in furnishing materials, or performing labor for or in construction of such railroad, depot buildings, water tanks, or any part thereof, in addition to his rights under sections 1311.39 and 1311.40 of the Revised Code, has a lien for its payment upon such railroad. Such lien has precedence over any lien take...

...abor performed, the time when the contractor or subcontractor for whom, and the section and place where, on the line of the road the labor was performed, or material furnished, and the amount due therefor, after deducting all payments and setoffs. In case of boarding, such affidavit must have attached thereto an itemized account thereof, showing the name of the contractor or subcontractor on whose order it was...

...otice shall contain a statement of the facts of his filing such affidavit, the county wherein filed, the amount of his claim, whether for labor, materials, or boarding furnished, and the contractor or subcontractor for whom rendered. When the notice cannot be served in the county where the affidavit is filed, it shall be served by the recorder upon the representative of the railroad by depositing in the post office a...

...A person obtaining and holding a lien as provided for in sections 1311.41 to 1311.43, inclusive, of the Revised Code, in addition to his remedies under sections 1311.38 to 1311.47, inclusive, of the Revised Code may proceed by petition as in other cases of lien, against the owner of and all other persons interested, as lienholders or otherwise, in such a railroad, and obtain such judgment as justice and equity requi...

...Each contractor or subcontractor shall have at least five days' notice, in writing, of the time when a lien for labor, boarding, or materials furnished under a contract with him will be paid, which notice may be served upon him personally or upon his authorized agent or foreman, by the owner of the railroad, or any officer or agent thereof, stating therein the time of their payment. On request of such contractor or s...

...aimant, in such case, shall commence an action on his claim before the proper tribunal, within forty days after notice that it has been disputed, and prosecute it to final judgment without delay. The amount thus ascertained or adjudicated shall then be paid by the railroad owner. After notice given as provided in section 1311.45 of the Revised Code, if no objection is filed against such claim within ten days after t...

... or implements on the order of any contractor or subcontractor, for his own use, or the use of persons employed by him while furnishing materials or labor for or in construction of such railroad. The amount of such claim shall not exceed the wages of the person performing labor or furnishing materials, to whom furnished, or the amount found due such contractor, or subcontractor, under sections 1311.38 to 1311.47, inc...

...g lawful custody of an animal, who contracts for food, board, or professional services for such animal. Any person who feeds or boards an animal under contract with the owner shall have a lien on such animal to secure payment for food and board furnished.

...If the owner of an animal, upon written demand by the lienholder, fails to satisfy a lien acquired under section 1311.48 of the Revised Code the lienholder may sell the animal at public sale to satisfy such lien, provided that before the animal is offered for sale the lienholder shall give ten days' notice of the time and place of sale in a newspaper of general circulation in the county where food or board was furnis...

...The keeper of any stallion, jack, or registered pure-bred bull, has a lien upon its get for the period of twelve months after birth thereof, for the payment of the service of such stallion, jack, or bull.

...A keeper or owner of any stallion, jack, or registered pure-bred bull may enforce his lien for service by replevin of the property before any county or municipal court having territorial jurisdiction where it is found. Upon gaining possession thereof, on first giving ten days' notice to the reputed owner of his intention to do so, he may sell it at public sale after two weeks' notice of the time and place of sale by ...

...roduct under an express or implied contract to an agricultural product handler, or an agricultural product handler who delivers an agricultural product under an express or implied contract to another agricultural product handler, has a lien to secure the payment for all of the agricultural product delivered under that contract. The lien attaches to the product, whether in a raw or processed condition, while in ...

...s a series of deliveries under the contract, the name of the agricultural product handler to whom the agricultural product was delivered, and the amount owed the lien claimant by the handler. If there was no agreed price at the time of delivery or first delivery, the lien claimant shall include in the affidavit the pricing method which the lien claimant and handler agreed to utilize in their contract to determine the...

... a series of deliveries under the contract, of the agricultural product has priority over all liens, claims, or encumbrances except wage and salary claims of workers who have no ownership interest in the business of the agricultural product handler, warehouse's liens as provided in section 1307.209 of the Revised Code, and amounts owed by the lienholder to the handler that are subject to setoff, and except that...

...Executors and administrators of deceased owners, part owners, and lessees have the rights and are subject to the liabilities, under this chapter, that such owners, part owners, and lessees would enjoy and be subject to, if alive.

...As used in sections 1311.71 to 1311.80 of the Revised Code: (A) "Aircraft" has the same meaning as in section 4561.01 of the Revised Code and includes any part or equipment of the aircraft. "Aircraft" includes an abandoned aircraft, unless otherwise specified. (B) "Abandoned aircraft" means an aircraft to which both of the following apply: (1) It is located on the premises of a public-use airport. (2) The own...

...(A) Except as provided in division (B) of this section, any person who performs labor upon, stores, or furnishes materials for an aircraft has a lien upon the aircraft to secure payment for the labor, storage, and materials. Except as provided in division (B) of this section, any person who owns or operates an airport or repair shop and whose employee performs labor upon, stores, or furnishes materials for an aircraf...

...ropriate records of the airport and contact both of the following entities to determine the name and address of the last registered owner: (1) The federal aviation administration's aircraft registration branch; (2) The office of aviation. (B)(1) Within twenty business days after receipt of the information obtained under division (A) of this section, the director shall send notice to the owner of the abandoned a...

...onably identifies it including the manufacturer, model, serial number, and registration number of the aircraft; (c) The name of the person for whom the labor was performed, the storage was provided, or the materials were furnished, if applicable; (d) The name of the owner of the aircraft, if known; (e) The name and address of the lien claimant; (f) The date that the lien claimant or the lien claimant's employ...

...(A) Any lien claimant who files an affidavit pursuant to section 1311.73 of the Revised Code shall serve to the owner of the aircraft that is subject to the lien, or to his agent, a copy of the affidavit within thirty days after filing the affidavit with the United States federal aviation administration. The lien claimant shall mail the copy of the affidavit by certified mail, or if the copy of the affidavit is retur...

...(A) A lien claimant who perfects a lien in accordance with section 1311.73 of the Revised Code has priority over all other liens, claims, or encumbrances, except wage and salary claims of workers who have no ownership interests in the business of the lien claimant and amounts that are owed by the lien claimant to the aircraft owner and that are subject to setoff against the amounts due for the labor, storage, and mat...

...1.72 of the Revised Code by bringing an action to recover the monetary amount secured by the lien in a court having jurisdiction in the county in which either of the following occurred: (1) The storage took place, the labor that is the basis of the lien was performed, or the materials that are the basis of the lien were furnished; (2) The county in which the lien claimant's primary place of business is located, i...