Ohio Revised Code Search

...(A) The assessments estimated in accordance with section 6131.14 of the Revised Code shall be payable in not less than two semiannual installments. At the time of the final hearing, in the order approving the levying of the assessments, the board of county commissioners shall determine how long a period of time, in semiannual installments, as taxes are paid, shall be given the owners of land benefited to pay the asse...

...(A) The board of county commissioners shall fix a date, time, and place at the final hearing for the county engineer to receive bids. The county engineer shall prepare the necessary bid documents and legal advertisements as provided in sections 307.87 and 307.88 of the Revised Code. (B) If an appeal has been taken to the court of common pleas, as provided in section 6131.25 of the Revised Code, the bids may be rece...

...(6) Is the award for compensation or damages just? (B) The appeal may be taken from any order affecting any part of the improvement as well as from any order affecting the entire improvement.

...If an appeal is filed pursuant to section 6131.25 of the Revised Code, the clerk of the board of county commissioners shall promptly prepare a transcript of the orders made by the board of county commissioners, and shall file such transcript with the clerk of the court of common pleas, together with the permanent files of records of the proceedings maintained by the board of county commissioners and county engineer a...

...Several owners may appeal from the orders in the same improvement. If several owners appeal, only one transcript need be made by the clerk of the board of county commissioners. All the appeals shall be filed in one action in the court of common pleas, which court, on any appeal, may separate for hearing or trial the issues appealed to said court, and render its order, judgment, or decree upon the issues as the same a...

...o be levied and the compensation and damages to be paid. (B) If the court orders the county engineer to make a survey and file the engineer's reports, plans, and schedules, the court also shall enter an order for transfer from the general revenue funds of the county to the general drainage improvement fund a sum of not more than twenty-five per cent of the engineer's preliminary estimate.

... in the schedules of assessments and damages by mail and by publication, as provided in sections 6131.01 to 6131.64 of the Revised Code. The notice shall be the same as the notice given when the schedules are filed with the clerk of the board of county commissioners, except that the notice shall state the date and time of the hearing in the court of common pleas, and proof of the notice shall be made by the certifica...

...or refusing to allow compensation or damages, the owners interested shall have the right of trial by jury. The jury may view the premises, as in other civil cases.

...s on the question of compensation or damages or if there are issues as to different properties, the court may submit all the several claims and issues to the same jury, with appropriate verdicts as to each claim. The court also may direct separate trials for the separate claims and issues. The court shall instruct the jury that it shall not consider or deduct the value of any benefits that such land will receive from...

...lants, on claims for compensation or damages, do not recover a judgment for more than the amount of compensation or damages awarded by the board of county commissioners, the costs on the hearing as to compensation or damages on appeal shall be taxed against the appellants. If the amount recovered is greater than the amount awarded by the board, the costs shall be taxed against the county. The prosecuting attorney s...

...mit the schedules of assessments and damages to the county auditor. The board of county commissioners and the county engineer shall proceed with letting contracts and constructing the improvement, and the county auditor shall proceed to levy and collect assessments and to pay compensation and damages as if no appeal had been taken. If an appeal is filed pursuant to section 6131.25 of the Revised Code, the board and t...

...sum shall be paid into the general drainage improvement fund.

...The county engineer shall prepare the documents as specified in section 6131.24 of the Revised Code. If the improvement requires both labor and material that is used in and remains a part of the improvement, the bids referred to in section 6131.37 of the Revised Code shall state separately the bidder's offer upon each and for each bid item indicated on the form. If the plans or specifications do not name a specific g...

...y find will be more economical or advantageous than the aggregate bid of a single bidder, but no bid shall be accepted for any part or thing that exceeds the estimate of the engineer unless only by such acceptance can a contract for the completion of an entire improvement be let for less than the aggregate estimate of the total improvement. If it is found that all bids for work and material, or all bids for any sepa...

...The acceptance of the bids in accordance with section 6131.40 of the Revised Code shall be approved by the board of county commissioners. Upon the acceptance of any bid for the whole or any part of an improvement, the bidder shall within ten days enter into a contract in writing to perform the work or furnish the material bid for as prepared by the county engineer. The board by an order entered on its journal shall r...

...Any owner who is assessed for the construction of any improvement may bring an action to enjoin the payment of any money owed a contractor who has not constructed the work according to the contract and specifications until the contractor has constructed the improvement according to the contract and specifications. The remedies provided in this section are in addition to all other remedies provided by law.

...location, engineering, compensation, damages, and contingency and the assessment for maintenance for one year, shall be levied upon each parcel of land, each public corporation, and each department, office, or institution of the state as stated in the schedules as of the date of the order of the board approving the contracts and ordering the levying of the assessments. (B) The auditor shall notify the owners of al...

...zed extensions of time as liquidated damages from any money due or to become due the contractor or his bondsmen unless the extension of time is due to an unforeseeable cause beyond the control and without the fault or negligence of the contractor.

...All work on an improvement and all materials furnished for use therein shall be under the supervision and inspection of the county engineer or a deputy appointed by him for the purpose. All material furnished under the specifications and contract shall be inspected by him before use and within a reasonable time after the same is delivered and placed upon the line of the improvement or such other place as is designate...

...not conform with the design of the drainage improvement for removal and replacement or repair as the engineer considers necessary. (B) If the county engineer determines that the culverts and bridges were adequate in capacity or vertical and horizontal alignment at the time of their installation, the removal and replacement shall be made at the expense of the project less any costs, which shall be apportioned by the...

...provide and establish the "general drainage improvement fund," to be used as a sinking fund for all bonds issued under sections 6131.01 to 6131.64, inclusive, of the Revised Code. (B) The fund may consist of any of the following: (1) Any taxes levied and collected for ditch and drainage purposes under county levies, not by law otherwise disposed of; (2) The proceeds of all bonds issued and sold under sections ...

...ment, may be paid from the general drainage improvement fund. (B) The letting and approving of any contract for an improvement shall be considered a specific appropriation of the amount of the obligation, and that amount shall be set apart for the purpose of the payment and contingently charged against the fund. If at any time the fund contains the proceeds of bonds or notes issued and sold under such sections, th...

...x shall be credited to the general drainage improvement fund. (B) For the purposes of this chapter and Chapters 6133., 6135., and 6137. of the Revised Code, the board of county commissioners may levy a tax under division (X) of section 5705.19 of the Revised Code upon all of the property listed and assessed for taxation in the county. In addition to the actions required under section 5705.19 of the Revised Code, th...

...The board of township trustees of a township to which is apportioned by the board of county commissioners a portion of the expenses of the construction of an improvement shall levy annually upon the grand duplicate of the township a tax sufficient to pay said apportionment, but not to exceed five tenths of one mill on a dollar, and shall certify this to the county auditor on or before the fifteenth day of May in each...

...vised Code, the board of education of a school district interested in land granted by congress for the support of public schools, unless such land has been permanently leased, and of a school district owning or holding other land for school purposes, when an assessment is made upon said land under such sections, shall pay for such assessment out of the contingent fund of the school district. If necessary for such pu...