Ohio Revised Code Search

...The board of appraisers of a sanitary district shall prepare a report of its findings which shall be arranged in tabular form and bound in book form, and which shall be known as the "sanitary district appraisal record." In case the purposes of the district include both improved sanitation and improved water supply, the board shall prepare a separate report for each purpose. Such record shall contain the name of the o...

...f the board of appraisers of a sanitary district under section 6115.33 of the Revised Code, the clerk of the court shall give notice by publication thereof, as provided in section 6115.01 of the Revised Code, in each county in the district. The notice shall be substantially as set forth in division (E) of section 6115.79 of the Revised Code. It is not necessary for the clerk to name the parties interested. It is not...

...y the board of appraisers of a sanitary district, or may acquiesce in the board's failure to appraise damages in his favor, and shall be construed to have done so unless within ten days after the last publication provided for in section 6115.34 of the Revised Code he files exceptions to said report or to any appraisal of either benefits or damages or of land to be taken which may be appropriated. All exceptions shall...

...f the board of appraisers of a sanitary district as modified and amended, and such findings and appraisals are final and incontestable. If the court finds that the estimated benefits appraised are less than the total costs of the execution of the official plan, exclusive of interest on any bonds issued to finance the official plan, or that the official plan is not suited to the requirements of the district, it may re...

...f the board of appraisers of a sanitary district, file with the clerk of the court a written notice making demand for a jury trial, specifying the award or awards from which the appeal is taken. If the appellant does not recover more by the verdict of the jury than the sum awarded him by the board, or if the verdict is not more favorable to him, he shall pay the costs of the appeal. The appeal shall be from the awar...

... the board of directors of the sanitary district may pay the amount allowed into court in money with the costs, and thereupon the court shall make an order admitting the district into possession of the property and confirming its title thereto, although the owner may take steps to take the case to a higher court. Thereupon the board may enter into undisturbed possession of the property and rights involved.

...f the board of appraisers of a sanitary district, the clerk of said court in which the same is entered shall transmit a certified copy of the decree, and of the appraisals as confirmed by the court, except those parts from which appeals have been perfected but not determined, to the secretary of the sanitary district. When any appeal has been finally determined, the clerk of that court shall certify the amount of ea...

...The board of directors of a sanitary district may at any time, when necessary to fulfill the objects for which the district was created, alter or add to the official plan. When such alterations or additions are formally approved by the board, by the environmental protection agency, and by the court, and are filed with the secretary of the sanitary district, they shall become part of the official plan for all purposes...

.... The board of directors of a sanitary district may appeal from any order of the court of common pleas made in any proceedings under such sections not requiring the intervention of a jury. The failure to appeal from any order of the court in any proceedings under sections 6115.01 to 6115.79, inclusive, of the Revised Code, within the time specified in such sections constitutes a waiver of any irregularity in the pr...

...If any lands in any sanitary district are not liable for taxation or assessment at the time of the execution of the work, but afterwards, during the period when such work is being paid for, become liable to taxation or assessment by reason of some change in condition, benefit, or ownership, such lands shall thereupon be appraised and assessed as other lands in said district receiving equal benefits.

...property within or without any sanitary district is benefited which for any reason was not appraised in the original proceedings, or was not appraised to the extent of benefits received, or in case any person, public corporation, or other district makes use of or profits by the works of any district to a degree not compensated for in the original appraisal, or in case the board of directors of the sanitary district f...

... the board of directors of the sanitary district or on the application of any holder of any bonds which have been issued pursuant to such sections, shall promptly and without delay remedy all defects or irregularities as the case requires by directing the board of appraisers of the sanitary district to make, in the manner provided in section 6115.30 of the Revised Code, a new appraisal of the amount of benefits again...

...The moneys of every sanitary district shall consist of three separate funds: (A) The "preliminary fund" consisting of the proceeds of the ad valorem tax authorized by section 6115.46 of the Revised Code, and such advancements as are made from the general county funds as provided in section 6115.46 of the Revised Code; (B) The "bond fund" consisting of the proceeds of levies made against the special assessments of b...

...tion for the organization of a sanitary district, and before the district is organized, the costs of publication and other official costs of the proceedings shall be paid out of the general funds of the county in which the petition is pending. Such payment shall be made on the warrant of the county auditor on the order of the court. If the district is organized, such cost shall be repaid to the county out of the firs...

...k, the board of directors of a sanitary district may borrow money at a rate of interest not exceeding six per cent per annum; may issue and sell or pay to contractors or others negotiable warrants signed by the members of the board; and may pledge, after it has been levied, the preliminary tax of not exceeding three tenths of a mill for the repayment thereof. If any warrant issued by the board is presented for paymen...

...iled with the secretary of the sanitary district as provided in section 6115.39 of the Revised Code, then from time to time, as the affairs of the district demand it, the board of directors of the sanitary district may levy on all real property, upon which benefits have been appraised, an assessment of such portion of the benefits as is found necessary by the board to pay the cost of the execution of the official pla...

...d on file in the office of the sanitary district, notice by publication shall be given to property owners that they may pay their assessments. Any owner of real property assessed for the execution of the official plan under section 6115.48 of the Revised Code may pay such assessment to the treasurer of the sanitary district within thirty days from the time such assessment is placed on file in the office of the distri...

...e, the board of directors of a sanitary district may issue bonds in anticipation of the levy and collection of special assessments in an amount not to exceed ninety per cent of the total amount of the assessments, exclusive of interest, levied under section 6115.48 of the Revised Code, in denominations of not less than one thousand dollars, bearing interest from date of issue at a rate determined as authorized in sec...

...The treasurer of a sanitary district shall, at the time of taking office, execute and deliver to the president of the board of directors of the sanitary district, a bond with good and sufficient sureties, to be approved by the board, conditioned that the treasurer shall account for and pay over as required by law, and as ordered by the board, all money received by him on the sale of any of such bonds or from any othe...

...A) The board of directors of a sanitary district may issue revenue obligations as provided in this section to pay the costs of the acquisition, construction, improvement, furnishing, and equipping of real and personal property appropriate for execution of the official plan. Such revenue obligations shall be authorized by resolution of the board of directors of a sanitary district. (B) Revenue obligations may be secu...

...ment of a water supply for the sanitary district, and to strengthen, repair, and restore the same, when needed, and to defray the current expenses of the district, other than those expenses connected with the water supply of the district, the board of directors of the sanitary district may, upon the substantial completion of the improvements and on or before the first day of September in each year thereafter, levy an...

...age or value of the lands in a sanitary district file a petition with the clerk of the court in whose office the petition was filed, stating that there has been a material change in the values of the property in the district since the last previous appraisal of benefits, and praying for a readjustment of the appraisal of benefits for the purpose of making a more equitable basis for the levy of the maintenance assessm...

...The board of directors of a sanitary district shall each year after the original assessment has been levied determine, order, and levy the part of the total assessments levied under this chapter, which shall become due and be collected during each year at the same time that state and county taxes are due and collected, which annual levy shall be evidenced and certified by the board not later than the first day of Sep...

...ach county in which lands of a sanitary district lie shall make due report to the county auditor of the sums collected by him. The auditor shall issue his warrant payable to the treasurer of the sanitary district for all sums of money in the hands of the county treasurer according to his report. Said auditor shall, as soon as the books for collection are closed by the county treasurer according to law, make report to...

...lands or other property of the sanitary district are located shall execute to the board of directors of the sanitary district a bond with at least two good and sufficient sureties or a surety company, which bond shall be paid for by the district, in a sum not less than the probable amount of any annual levy of the assessment to be collected by him during any one year, conditioned that said treasurer shall pay over a...