Ohio Revised Code Search

...(A) The assessments estimated in accordance with section 6131.14 of the Revised Code shall be payable in not less than two semiannual installments. At the time of the final hearing, in the order approving the levying of the assessments, the board of county commissioners shall determine how long a period of time, in semiannual installments, as taxes are paid, shall be given the owners of land benefited to pay the asse...

...(A) The board of county commissioners shall fix a date, time, and place at the final hearing for the county engineer to receive bids. The county engineer shall prepare the necessary bid documents and legal advertisements as provided in sections 307.87 and 307.88 of the Revised Code. (B) If an appeal has been taken to the court of common pleas, as provided in section 6131.25 of the Revised Code, the bids may be rece...

...(A) Any affected owner may appeal to the court of common pleas within thirty days of the date that any order was issued by the board of county commissioners under this chapter, and may appeal any one or more of the following questions: (1) Is the improvement necessary? (2) Will the improvement be conducive to the public welfare? (3) Is the cost of the improvement greater than the benefits conferred? (4) Is th...

...If an appeal is filed pursuant to section 6131.25 of the Revised Code, the clerk of the board of county commissioners shall promptly prepare a transcript of the orders made by the board of county commissioners, and shall file such transcript with the clerk of the court of common pleas, together with the permanent files of records of the proceedings maintained by the board of county commissioners and county engineer a...

...Several owners may appeal from the orders in the same improvement. If several owners appeal, only one transcript need be made by the clerk of the board of county commissioners. All the appeals shall be filed in one action in the court of common pleas, which court, on any appeal, may separate for hearing or trial the issues appealed to said court, and render its order, judgment, or decree upon the issues as the same a...

...ters appealed de novo. The court, exercising equitable jurisdiction, shall bring the entire proceedings before it in order to determine all the issues raised in the proceedings and enter a final judgment, order, or decree for or against the improvement petitioned for and for or against the assessments to be levied and the compensation and damages to be paid. (B) If the court orders the county engineer to make a sur...

...sioners made at the first hearing dismissing the petition, and if the court of common pleas from the evidence adduced, including the county engineer's preliminary estimate of cost and preliminary report on feasibility of the project, but without a survey having been made by the county engineer and without any of the schedules, plans, or reports having been filed by the engineer, finds that the construction of the imp...

...of county commissioners allowing or refusing to allow compensation or damages, the owners interested shall have the right of trial by jury. The jury may view the premises, as in other civil cases.

...If there is more than one appellant in a trial by jury authorized under section 6131.32 of the Revised Code with separate claims on the question of compensation or damages or if there are issues as to different properties, the court may submit all the several claims and issues to the same jury, with appropriate verdicts as to each claim. The court also may direct separate trials for the separate claims and issues. Th...

...If the appellants, on claims for compensation or damages, do not recover a judgment for more than the amount of compensation or damages awarded by the board of county commissioners, the costs on the hearing as to compensation or damages on appeal shall be taxed against the appellants. If the amount recovered is greater than the amount awarded by the board, the costs shall be taxed against the county. The prosecutin...

...(A) After the final judgment, order, or decree upon any appeal is rendered by the court of common pleas, the clerk of the court of common pleas shall, within twenty-one days, make a transcript of the same and shall certify and transmit it with all original papers in the case to the clerk of the board of county commissioners, who shall forthwith enter the judgment, order, or decree upon the journal of the board. If th...

...If no appeal has been taken to the court of common pleas at the time fixed in the notice to receive bids as provided by section 6131.24 of the Revised Code, or if an appeal has been taken at the time as stated in the notice given after the appeal has been determined, the county engineer shall receive bids. The contracts, bids, bonds, and bid guaranties shall be handled in accordance with sections 153.12 to 153.14 and...

...The county engineer shall prepare the documents as specified in section 6131.24 of the Revised Code. If the improvement requires both labor and material that is used in and remains a part of the improvement, the bids referred to in section 6131.37 of the Revised Code shall state separately the bidder's offer upon each and for each bid item indicated on the form. If the plans or specifications do not name a specific g...

...dvantageous than the aggregate bid of a single bidder, but no bid shall be accepted for any part or thing that exceeds the estimate of the engineer unless only by such acceptance can a contract for the completion of an entire improvement be let for less than the aggregate estimate of the total improvement. If it is found that all bids for work and material, or all bids for any separate part of work and material, are...

...The acceptance of the bids in accordance with section 6131.40 of the Revised Code shall be approved by the board of county commissioners. Upon the acceptance of any bid for the whole or any part of an improvement, the bidder shall within ten days enter into a contract in writing to perform the work or furnish the material bid for as prepared by the county engineer. The board by an order entered on its journal shall r...

...Any owner who is assessed for the construction of any improvement may bring an action to enjoin the payment of any money owed a contractor who has not constructed the work according to the contract and specifications until the contractor has constructed the improvement according to the contract and specifications. The remedies provided in this section are in addition to all other remedies provided by law.

...(A) Upon the completion of the work and the approval of it by the county engineer, the board of county commissioners shall order the county auditor to reduce pro rata the assessments confirmed by it by the difference between the estimated cost of the construction and the final cost as certified by the county engineer. The assessments so reduced, including the cost of location, engineering, compensation, damages, and ...

...y extended. Any order extending or refusing to extend the contract time shall be by resolution entered on the journal of the board. The affidavit shall be filed in the proceedings. Upon the recommendations of the county engineer, the board of county commissioners may deduct the costs of engineering and inspection incurred by the county during the tenure of the authorized extensions of time as liquidated damages fro...

...All work on an improvement and all materials furnished for use therein shall be under the supervision and inspection of the county engineer or a deputy appointed by him for the purpose. All material furnished under the specifications and contract shall be inspected by him before use and within a reasonable time after the same is delivered and placed upon the line of the improvement or such other place as is designate...

...(A) The county engineer shall evaluate all culverts and bridges, except those on state and federal highways, for adequacy of capacity, vertical and horizontal alignment, and stability. The county engineer shall schedule any bridge or culvert that does not conform with the design of the drainage improvement for removal and replacement or repair as the engineer considers necessary. (B) If the county engineer determin...

...nage improvement fund," to be used as a sinking fund for all bonds issued under sections 6131.01 to 6131.64, inclusive, of the Revised Code. (B) The fund may consist of any of the following: (1) Any taxes levied and collected for ditch and drainage purposes under county levies, not by law otherwise disposed of; (2) The proceeds of all bonds issued and sold under sections 6131.01 to 6131.64, inclusive, of the R...

...(A) All costs and expenses of improvements under this chapter, including contract prices of construction and the costs of locating the improvement, may be paid from the general drainage improvement fund. (B) The letting and approving of any contract for an improvement shall be considered a specific appropriation of the amount of the obligation, and that amount shall be set apart for the purpose of the payment and ...

...(A) If necessary, the board of county commissioners, each March, shall levy upon the grand duplicate of the county a tax, not to exceed five-tenths of one mill on the dollar, that is sufficient to pay for the location and construction of the portions of the respective improvements located by the board or for which the county has been assessed under this chapter or Chapter 6133., 6135., or 6137. of the Revised Code. W...

...The board of township trustees of a township to which is apportioned by the board of county commissioners a portion of the expenses of the construction of an improvement shall levy annually upon the grand duplicate of the township a tax sufficient to pay said apportionment, but not to exceed five tenths of one mill on a dollar, and shall certify this to the county auditor on or before the fifteenth day of May in each...

...If it is a party to an improvement under sections 6131.01 to 6131.64, inclusive, of the Revised Code, the board of education of a school district interested in land granted by congress for the support of public schools, unless such land has been permanently leased, and of a school district owning or holding other land for school purposes, when an assessment is made upon said land under such sections, shall pay for su...