Ohio Revised Code Search

... of ninety-two per cent of the invoice costs, not to exceed the bid price in a unit price contract, of material delivered on the site of the work, or a railroad station, siding, or other point in the vicinity of the work, or other approved storage site, provided such materials have been inspected and found to meet the specifications. The balance of such invoiced value shall be paid when such material is incorpo...

...n appropriate response action; (2) The cost of encapsulating or enclosing the asbestos hazard would be less than removing it. (B) As used in this section, "enclosure" and "encapsulation" have the meanings given in section 3710.01 of the Revised Code. (C) The requirements of this section do not apply to school districts.

...conjunction with the administration of public works contracts that the state or any institution supported in whole or in part by the state enters into for any project subject to sections 153.01 to 153.11 of the Revised Code. (B) Notwithstanding any contract provision to the contrary, any claim submitted under a public works contract that the state or any institution supported in whole or in part by the state ...

...(A) When in the opinion of the owner referred to in section 153.01 of the Revised Code, the work under any contract made under any law of the state is neglected by the contractor or such work is not prosecuted with the diligence and force specified or intended in the contract, such owner may make requisition upon the contractor for such additional specific force or materials to be brought into the work under such con...

...The owner referred to in section 153.01 of the Revised Code shall make separate estimates of all additional force or materials employed or supplied as provided by section 153.17 of the Revised Code, and payment shall be provided for by the director of budget and management. The amount so paid shall be charged against the contractor and be deducted from his next or any subsequent estimate. The amount or any part there...

...All contracts under sections 153.01 to 153.60, inclusive, of the Revised Code, shall contain provision in regard to the time when the whole or any specified portion of work contemplated therein shall be completed and that for each day it shall be delayed beyond the time so named the contractor shall forfeit to the state a sum to be fixed in the contract, which shall be deducted from any payment due or to become due t...

...The attorney general shall have charge of and direct the proceedings necessary to enforce contracts authorized by sections 153.01 to 153.19, inclusive, of the Revised Code.

...When the board of county commissioners has determined to erect a courthouse or other county building, or to make an addition to, or to make an improvement of any existing county owned building, the board may appoint four suitable and competent freehold electors of the county, who shall, together with the board, constitute a building commission and serve until the courthouse or other county building, or the addition t...

...The persons appointed under section 153.21 of the Revised Code after August 22, 1951, shall receive a reasonable compensation for the time actually employed, to be fixed by the court of common pleas and on its approval paid from the county treasury. Their compensation in the aggregate shall not exceed eight thousand dollars.

...The necessary expenses for stationery, postage, correspondence, and travel out of the county required in the discharge of the duties of the building commission shall be paid from the county treasury on the order of the board of county commissioners and the warrant of the county auditor.

...Except as otherwise provided in section 3.061 of the Revised Code, before entering upon the discharge of their duties, the persons appointed to the building commission shall each take an oath of office and give bond for the faithful and honest discharge of official duties in the same amount as required of members of the board of county commissioners, with sureties approved by the judge of the court of common pleas....

...In case of the death, resignation, or removal of any member of the building commission, the vacancy shall be filled by appointment by the judge of the court of common pleas as provided in section 153.21 of the Revised Code.

...vised Code, relating to the erection of public buildings of the county.

...The building commission may employ architects, superintendents, and other necessary employees during the construction of a courthouse or other county building and fix their compensation and bond.

...pecifications of work, and estimates of cost thereof shall be filed by the county auditor in his office and shall not be altered, unless such alteration is first drawn, specified, and estimated as required by law for the original plans and approved by the commission. No such change shall be made until the price to be paid therefor has been agreed upon in writing between the commission and the contractor.

...Resolutions for the adoption or alteration of plans or specifications, or for the award of contracts, hiring of architects, superintendent, or other employees and the fixing of their compensation, the approval of bonds or bid guaranties, and the allowance of estimates shall be in writing and shall require for their adoption the votes of five members of the building commission, taken by yeas and nays recorded on the j...

...pecifications of work, and estimates of costs in detail and in the aggregate pertaining to the building.

...h item of expense, and of the aggregate cost thereof. (B) In connection with the planning and construction of any public building project, the board may employ a construction project manager or consultants, and fix their compensation. Such construction project manager or consultants shall be expert and qualified in their respective fields. The cost of such services may be paid from the proceeds of bonds and notes i...

...tions of the work, so long as the total cost of construction of a project, which may include more than one building, is reasonably estimated by the board to exceed fifteen million dollars.

...When it becomes necessary to erect a bridge, the board of county commissioners shall determine the length and width of the superstructure, and whether it shall be single or double track, and it shall advertise for bids for performing the labor and furnishing the materials necessary to the erection thereof in accordance with sections 307.86 to 307.92 of the Revised Code.

...The board of county commissioners may also invite, receive, and consider bids on any other plan at the option of bidders, and shall require that any such plan together with specifications shall be filed in the office of the county auditor for a period of fifteen days prior to the date for receiving bids. Such plans and specifications shall show the number of spans, the length of each, the nature, quality, and size of...

...In its advertisement, the board of county commissioners shall invite bidders to make bids for furnishing all the materials and performing all the work, or for such parts thereof as bidders deem proper, and include such other matter as is required in section 307.87 of the Revised Code.

...The plans and specifications upon which the contracts are awarded, shall be kept on file in the office of the board of county commissioners and made a part of the contract with the successful bidder. When it is necessary to alter, repair, or make an addition to a bridge, the board of county commissioners in making contracts therefor, shall conform to sections 153.01 to 153.60, inclusive, of the Revised Code, in relat...

...fications of work, and estimates of the cost thereof in detail and in the aggregate, required in sections 153.31 to 153.35, inclusive, of the Revised Code, relate to the building of a courthouse or jail, or an addition to or alteration, repair, or improvement thereof, they shall be submitted to the board of county commissioners. If the estimated total cost of the project is greater than seventy-five thousand dollars,...

...ifications of work and estimates of the cost thereof relate to the building, addition to, or alteration of a county home, they shall be submitted to the board of county commissioners. If approved by a majority of the board, a copy thereof shall be deposited in the office of the board of county commissioners and kept for the inspection and use of parties interested.