Ohio Revised Code Search

... the Revised Code may submit a written complaint to the permittee or to the chief of the division of water resources if both of the following apply: (1) The owner obtains all or part of the owner's water supply for domestic, agricultural, industrial, or other legitimate use from ground water. (2) There is a diminution or interruption of that water supply. The owner shall include in the complaint the owner's nam...

...shall bring the action in the court of common pleas of Franklin county or the county where the applicable facility is located. In an action for injunction, any factual findings of the chief presented at a hearing conducted under section 1522.21 of the Revised Code is prima facie evidence of the facts regarding the order that is the subject of the hearing. (C) A person who violates any provision of this chapter, any...

...ed by the Ohio facilities construction commission or by any other state officer or state agency authorized by law to administer a project, including an educational institution listed in section 3345.50 of the Revised Code, is to be erected or constructed, whenever additions, alterations, or structural or other improvements are to be made, or whenever heating, cooling, or ventilating plants or other equipment is to be...

...tate capital funds, including moneys from the education facilities trust fund, is to be erected or constructed, or whenever additions, alterations, or structural or other improvements are to be made, if any steel products are to be purchased for or provided in the construction, repair, or improvement project, only steel products as defined in division (F) of this section shall be purchased for or provided in t...

... or in part by contributions or loans from any agency of the United States government, preference shall be given to contractors having their principle place of business in Ohio over contrctors having their principle place of business in a state which provides a preference in that state in favor of contractors of that state for the same type of work. Where a preference is provided by another state for contractors of t...

...e quantity contract for an architect or engineer on an on-call, multi-project basis, to advise and consult with the capitol square review and advisory board for a defined contract period. To enter into an indefinite delivery indefinite quantity contract the executive director shall do all of the following: (1) Prepare bidding documents; (2) Establish contract forms; (3) Determine contract terms and conditions, ...

...od and may rescind the debarment at any time upon notification to the contractor. During the period of debarment, the contractor is not eligible to bid for or participate in any contract for a public improvement as referred to in section 153.01 of the Revised Code or for a project as defined in section 3318.01 of the Revised Code. After the debarment period expires, the contractor may be eligible to bid for and parti...

...nate an employee's employment the first time the employee tests positive for drugs or alcohol or if an employee refuses to be tested for drugs, alcohol, or both. (C) Any time the United States department of health and human services changes the federal testing model that the administrator has incorporated into the bureau's drug-free workplace program in a manner that allows additional or new products, protocols...

...The general assembly intends the drug-free workplace programs required by section 153.03 of the Revised Code to be limited to the constructing, altering, or repairing of public improvements of the state and to be of assistance in ensuring that such public improvements are constructed, altered, or repaired in a manner that protects the safety of the citizens of this state.

...d by the Ohio facilities construction commission. The life-cycle costs shall be a primary consideration in the selection of a design. The same shall be deposited and safely kept in the office of the owner as defined in section 153.01 of the Revised Code as the property of the state.

...ation of the claimant within one year from the date of delivering or furnishing such labor or material, in the court of common pleas of the county wherein such labor or material was furnished or delivered. Such bond shall not be released by the execution of any additional security, notes, retentions from estimates, or other instrument on account of such claim, or for any reason, except the full payment of such claim ...

...d Code shall give public notice of the time and place when and where bids will be received for performing the labor and furnishing the materials of such construction, improvement, alteration, addition, or installation, and a contract awarded, except for materials manufactured by the state or labor supplied by a county department of job and family services that may enter into the same. The form of bid approved ...

...bids, in a manner as prescribed by the commission. Copies of the plans, details, estimates of cost, and specifications shall be available electronically and open to public inspection at all business hours between the day of the first publication and the day for opening the bids, at the office of the commission where the bids are received, and such other place as may be designated in such notice.

...ed by the Ohio facilities construction commission. A bid shall be invalid and not considered unless a bid guaranty meeting the requirements of section 153.54 of the Revised Code and in the form approved by the commission is filed with such bid. For a bid that is not filed electronically, the bid and bid guaranty shall be filed in one sealed envelope. If the bid and bid guaranty are filed electronically, they must be ...

...ia as the Ohio facilities construction commission directs. All contracts shall provide that such owner may make any change in work or materials on the conditions and in the manner provided in sections 153.10 and 153.11 of the Revised Code.

...inal papers. If such change affects the price, the amount thereof shall likewise receive such approval.

...Whenever the change referred to in section 153.10 of the Revised Code is approved by the owner as defined in section 153.01 of the Revised Code, accepted in writing by the contractor, and filed, the same shall be considered as being a part of the original contract, and the bond theretofore executed shall be increased or decreased accordingly to include and cover the change in the contract.

...on applies shall be entered into if the price of the contract, or, if the project involves multiple contracts where the total price of all contracts for the project, is in excess of ten per cent, in the case of a contract made by the state or a public board, commission, authority, or instrumentality of the state, or twenty per cent, in the case of a contract made by a county, township, municipal corporation, school d...

...ntract for payment to the person with whom it is made, the owner referred to in section 153.01 or 153.12 of the Revised Code shall approve a full, accurate, and detailed estimate of the various kinds of labor performed and material furnished under the contract, with the amount due for each kind of labor and material and the materials and amount due in the aggregate, which estimate shall be based upon actual measureme...

...he invoice costs, not to exceed the bid price in a unit price contract, of material delivered on the site of the work, or a railroad station, siding, or other point in the vicinity of the work, or other approved storage site, provided such materials have been inspected and found to meet the specifications. The balance of such invoiced value shall be paid when such material is incorporated into and becomes a part of s...

...(A) Whenever an asbestos hazard abatement activity is being performed in a building or structure supported in whole or in part by the state, an asbestos hazard evaluation specialist certified under Chapter 3710. of the Revised Code shall assess the hazard and determine appropriate response actions. Enclosure or encapsulation, rather than removal, shall be implemented if the asbestos hazard evaluation specialist deter...

... procedure guidelines for contract documents in conjunction with the administration of public works contracts that the state or any institution supported in whole or in part by the state enters into for any project subject to sections 153.01 to 153.11 of the Revised Code. (B) Notwithstanding any contract provision to the contrary, any claim submitted under a public works contract that the state or any institu...

...tract or to remove improper materials from the grounds as in their judgment the contract and its faithful fulfillment requires. Not less than five days' notice in writing of such action shall be served upon the contractor or the contractor's agent in charge of the work. If the contractor fails to comply with such requisition within fifteen days, such owner with the written consent of the Ohio facilities constructi...

...gainst the contractor and be deducted from his next or any subsequent estimate. The amount or any part thereof not so paid may be recovered by action from such contractor and his sureties.

... of work contemplated therein shall be completed and that for each day it shall be delayed beyond the time so named the contractor shall forfeit to the state a sum to be fixed in the contract, which shall be deducted from any payment due or to become due to the contractor.