Ohio Revised Code Search

...ent of natural resources, or the Ohio public works commission. (2) "Obligations" means obligations as defined in section 151.01 of the Revised Code issued to pay costs of projects for conservation purposes as referred to in division (A)(1) of Section 2o of Article VIII, Ohio Constitution and division (A)(1) of Section 2q of Article VIII, Ohio Constitution. (B)(1) The issuing authority shall iss...

...roperty therefore; and (e) Support for public and private institutions of higher education, research organizations or institutions, and private sector entities. (2) "Obligations" means obligations as defined in section 151.01 of the Revised Code issued to pay costs of projects for research and development purposes as referred to in division (A)(2) of Section 2p of Article VIII, Ohio Constitution. (3) "Project" mea...

...(A) As used in this section: (1) "Costs of sites and facilities" includes related direct administrative expenses and allocable portions of the direct costs of those projects. "Costs of sites and facilities" includes "allowable costs" as defined in section 122.085 of the Revised Code. (2) "Obligations" means obligations as defined in section 151.01 of the Revised Code issued to pay costs of sites and faciliti...

...(A) As used in this section: (1) "Bond proceedings" includes any trust agreements, and any amendments or supplements to them, as authorized by this section. (2) "Costs of revitalization projects" includes related direct administrative expenses and allocable portions of the direct costs of those projects of the department of development or the environmental protection agency. (3) "Issuing authority" means the...

...in part by the state or in or upon the public works of the state that is administered by the Ohio facilities construction commission or by any other state officer or state agency authorized by law to administer a project, including an educational institution listed in section 3345.50 of the Revised Code, is to be erected or constructed, whenever additions, alterations, or structural or other improvements are t...

...on, repair, painting or decoration of a public improvement, including any highway improvement, made by the state or in whole or in part supported by the state, except for a contract for products produced or mined in Ohio or for a contract financed in whole or in part by contributions or loans from any agency of the United States government, preference shall be given to contractors having their principle place of busi...

... do all of the following: (1) Prepare bidding documents; (2) Establish contract forms; (3) Determine contract terms and conditions, including the following: (a) The maximum overall value of the contract, which may include an allowable increase of five per cent of the advertised contract value; (b) The duration of the contract, not to exceed two years. (4) Take any other action necessary to fulfill the dut...

...constructing, altering, or repairing of public improvements of the state and to be of assistance in ensuring that such public improvements are constructed, altered, or repaired in a manner that protects the safety of the citizens of this state.

...The plans, details, bills of material, specifications of work, estimates of cost in detail and in the aggregate, life-cycle cost analysis, form of bid, bid guaranty, and other data that may be required shall be prepared on such material and in such manner and form as are prescribed by the Ohio facilities construction commission. The life-cycle costs shall be a primary consideration in the selection of a design....

...The bond required by section 153.08 of the Revised Code may be enforced against the person executing such bond, by any claimant for labor or material, and suit may be brought on such bond in the name of the state on relation of the claimant within one year from the date of delivering or furnishing such labor or material, in the court of common pleas of the county wherein such labor or material was furnished or delive...

...If in the opinion of the owner referred to in section 153.01 of the Revised Code, the award of a contract to the lowest responsive and responsible bidder is not in the best interests of the state, the owner may accept another bid so opened or reject all bids, and advertise for other bids. Such advertisement shall be for such time, in such form, and in such newspaper as the Ohio facilities construction commissio...

...After the plans, bills of material, specifications of work, estimates of cost in detail and in the aggregate, life-cycle cost analysis, form of bid, bid guaranty, and other data that may be required are approved and filed with the owner as defined in section 153.01 of the Revised Code, no change of plans, details, bills of material, or specifications shall be made or allowed unless the same are approved by the owner ...

...Whenever the change referred to in section 153.10 of the Revised Code is approved by the owner as defined in section 153.01 of the Revised Code, accepted in writing by the contractor, and filed, the same shall be considered as being a part of the original contract, and the bond theretofore executed shall be increased or decreased accordingly to include and cover the change in the contract.

...At the time named in the contract for payment to the person with whom it is made, the owner referred to in section 153.01 or 153.12 of the Revised Code shall approve a full, accurate, and detailed estimate of the various kinds of labor performed and material furnished under the contract, with the amount due for each kind of labor and material and the materials and amount due in the aggregate, which estimate shall be ...

...(A) Whenever an asbestos hazard abatement activity is being performed in a building or structure supported in whole or in part by the state, an asbestos hazard evaluation specialist certified under Chapter 3710. of the Revised Code shall assess the hazard and determine appropriate response actions. Enclosure or encapsulation, rather than removal, shall be implemented if the asbestos hazard evaluation specialist deter...

...conjunction with the administration of public works contracts that the state or any institution supported in whole or in part by the state enters into for any project subject to sections 153.01 to 153.11 of the Revised Code. (B) Notwithstanding any contract provision to the contrary, any claim submitted under a public works contract that the state or any institution supported in whole or in part by the state ...

...takeover contractor without competitive bidding or controlling board approval. When the owner has taken over a project after a default has occurred, any moneys that the owner receives from the surety as a settlement for completion of the project shall be deposited in the original fund from which the capital appropriation for the project was made. The executive director, without controlling board approval, may auth...

...The owner referred to in section 153.01 of the Revised Code shall make separate estimates of all additional force or materials employed or supplied as provided by section 153.17 of the Revised Code, and payment shall be provided for by the director of budget and management. The amount so paid shall be charged against the contractor and be deducted from his next or any subsequent estimate. The amount or any part there...

...All contracts under sections 153.01 to 153.60, inclusive, of the Revised Code, shall contain provision in regard to the time when the whole or any specified portion of work contemplated therein shall be completed and that for each day it shall be delayed beyond the time so named the contractor shall forfeit to the state a sum to be fixed in the contract, which shall be deducted from any payment due or to become due t...

...The attorney general shall have charge of and direct the proceedings necessary to enforce contracts authorized by sections 153.01 to 153.19, inclusive, of the Revised Code.

...When the board of county commissioners has determined to erect a courthouse or other county building, or to make an addition to, or to make an improvement of any existing county owned building, the board may appoint four suitable and competent freehold electors of the county, who shall, together with the board, constitute a building commission and serve until the courthouse or other county building, or the addition t...

...The persons appointed under section 153.21 of the Revised Code after August 22, 1951, shall receive a reasonable compensation for the time actually employed, to be fixed by the court of common pleas and on its approval paid from the county treasury. Their compensation in the aggregate shall not exceed eight thousand dollars.

...The necessary expenses for stationery, postage, correspondence, and travel out of the county required in the discharge of the duties of the building commission shall be paid from the county treasury on the order of the board of county commissioners and the warrant of the county auditor.

...Except as otherwise provided in section 3.061 of the Revised Code, before entering upon the discharge of their duties, the persons appointed to the building commission shall each take an oath of office and give bond for the faithful and honest discharge of official duties in the same amount as required of members of the board of county commissioners, with sureties approved by the judge of the court of common pleas....

...In case of the death, resignation, or removal of any member of the building commission, the vacancy shall be filled by appointment by the judge of the court of common pleas as provided in section 153.21 of the Revised Code.