Ohio Revised Code Search

...he board of appraisers of a conservancy district, file with the clerk of such court a written notice making demand for a jury trial, specifying the award or awards from which the appeal is taken. He shall at the same time file a bond with good and sufficient security to be approved by the clerk in the sum of not more than two hundred dollars to the effect that if the appellant does not recover more by the verdict of ...

...e board of directors of the conservancy district may pay the amount allowed into court in money with the costs, and, at that time, the court shall make an order admitting the district into possession of the property and confirming its title to the property, although the owner may take steps to take the case to a higher court. At that time, the board may enter into undisturbed possession of the property and rights inv...

...he board of appraisers of a conservancy district, the clerk of said court in which the same is entered shall transmit a certified copy of the decree, and of the appraisals as confirmed by the court, except those parts from which appeals have been perfected but not determined, to the secretary of the conservancy district. Upon the entry of the order of the court approving the report of the board, the clerk of the cou...

...ted to the secretary of the conservancy district as provided by section 6101.37 of the Revised Code, the board of directors of the conservancy district may deposit with the court the amount of any confirmed appraisal of compensation or damages, from the award of which no appeal has been taken, for any property or interest in property as included in the conservancy appraisal record and confirmed by the court. The cour...

...ction and disposal of sewage and liquid wastes requires the approval of the environmental protection agency. If the proposed alterations or additions materially modify the general character of the work, or materially modify the resulting damages or materially reduce the benefits for which the board is not able to make amicable settlement, or materially increase the benefits in such a manner as to require a new apprai...

...The board of directors of a conservancy district may appeal from any order of the court of common pleas made in any proceeding under this chapter not requiring the intervention of a jury. The failure to appeal from any order of the court in any proceedings under this chapter within the time specified in this chapter constitutes a waiver of any irregularity in the proceedings. The remedies provided for in this chapte...

...If any lands in any conservancy district are not liable for assessment at the time of the execution of the work, but afterwards, during the period when the work is being paid for, become liable to assessment by reason of some change in condition or ownership, the lands then shall be appraised and assessed as other lands in the district receiving equal benefits.

...ation within or without any conservancy district is benefited and for any reason the benefits were not appraised in the original proceedings or were not appraised to the extent of the benefits received, or if any person or public corporation makes use of or profit by the works of any district to a degree not compensated for in the original appraisal, or if the board of directors of the conservancy district finds it n...

...e board of directors of the conservancy district or on the application of any holder of any bonds or notes that have been issued pursuant to this chapter, shall promptly and without delay remedy, or cause to be remedied, all defects or irregularities as the case requires and, for the purpose, may direct the board of appraisers of the conservancy district to make, in the manner provided in section 6101.28 of the Revis...

...The moneys of every conservancy district shall be administered through the following funds: (A) The preliminary fund, consisting of the proceeds of the preliminary assessment levied under authority of section 6101.45 of the Revised Code, any advances of assessments obtained or notes issued in accordance with section 6101.46 of the Revised Code, and any contribution or appropriation by the state under authority of s...

...n or disorganization of any conservancy district organized pursuant to this chapter, the board of directors of the district shall determine the amount of funds of the district not needed for the payment of the expenses and indebtedness of the district and shall, upon the dissolution or disorganization, forthwith distribute the funds among the various counties comprising the district in the same proportion as the fund...

...n for the organization of a conservancy district, and before the district is organized, the costs of publication and other official costs of the proceedings shall be paid out of the general funds of the county in which the petition is pending. The payment shall be made on the warrant of the county auditor or on the order of the court. If the district is organized, the costs shall be repaid to the county out of the fi...

...the board of directors of a conservancy district may borrow money and issue notes therefor at a rate or rates of interest not exceeding the rate provided in section 9.95 of the Revised Code and in an amount not greater than seventy-five per cent of the unencumbered proceeds derived or derivable from the preliminary assessment levied, or which the board has authority to levy, under section 6101.45 of the Revised Code,...

...east in part, it benefits a conservancy district that includes all or parts of more than sixteen counties. (c) At least in part, its purposes are consistent with the purposes of a conservancy district that includes all or parts of more than sixteen counties. (2) "Financial support" means the provision of funds from a conservancy district that includes all or parts of more than sixteen counties to a charitable tru...

...d with the secretary of the conservancy district as provided in section 6101.37 of the Revised Code, from time to time, as the affairs of the district demand it, the board of directors of the conservancy district shall levy on all real property and on all public corporations, upon which benefits have been appraised, an assessment of the portion of the benefits that is found necessary by the board to pay the cost of t...

...n file in the office of the conservancy district, notice by publication shall be given to property owners and public corporations assessed that they may pay their assessments. Any owner of real property or public corporation assessed for the execution of the official plan under this chapter may pay the assessment to the treasurer of the conservancy district within thirty days from the time the assessment is placed on...

...The board of directors of a conservancy district may, if in its judgment it seems best, issue bonds in an amount not to exceed ninety per cent of the total amount of the unpaid portion of an assessment, exclusive of interest, levied under this chapter, to mature at annual or semiannual intervals within thirty years. Whenever the board determines to issue bonds in anticipation of the collection of the installments of ...

...A conservancy district or a subdistrict of it may issue revenue bonds for the purpose of paying all or part of the cost of acquiring or constructing any improvement that the district or subdistrict is authorized to acquire or construct, and the improvement may include equipment, land or interests in land, and facilities necessary or appropriate to the improvement. The bonds shall be secured only by a pledge of, and l...

...The treasurer of a conservancy district, at the time of taking office, shall execute to the district and deliver to the president of the board of directors of the district, a bond with good and sufficient sureties, to be approved by the board, conditioned that the treasurer shall account for and pay over as required by law, and as ordered by the board, all money received by the treasurer on the sale of bonds and note...

...ond to the treasurer of the conservancy district with a request for the conversion of the bond into a bond registered as to principal and interest, the treasurer shall cut off and cancel the coupons of the coupon bond presented, and shall stamp, print, or write upon the coupon bond, either upon the back or the face of it or in blanks provided for the purpose a dated and signed statement to the effect that the bond is...

...the current expenses of the conservancy district, the board of directors of the district may, upon the substantial completion of the improvements and on or before the thirtieth day of September in each year thereafter, levy an assessment upon each tract or parcel of land and upon each public corporation within the district, subject to assessments under this chapter, to be known as a conservancy maintenance assessment...

... or value of the lands in a conservancy district or the board of directors of a conservancy district file a petition with the clerk of the court having jurisdiction in the original case, stating that there has been a material change in the values of the property in the district or additional benefits are being derived from the works and the improvements of the district since the last previous appraisal of benefits, a...

...The board of directors of a conservancy district shall each year after the original assessment has been levied determine, order, and levy the annual levy, which shall include all assessments, or installments of assessments, together with interest, levied under this chapter, which become due in the ensuing year. The annual levy shall be due and be collected at the same time that state and county taxes are due and col...

...the board of directors of a conservancy district may borrow money and issue notes therefor; but the aggregate of such loans made in any year shall not exceed one half of the total amount estimated by the county auditors of the several counties in the district to be received from the collection of the assessments for such year, after deduction of all advances from such collection. Such estimate shall state separately ...

...ble to the treasurer of the conservancy district for all sums of money in the hands of the county treasurer, according to the report. The auditor, as soon as the records for collection are closed by the county treasurer according to law, shall make report to the treasurer of the district of the sums collected, and of the assessments not collected, as returned to the auditor by the county treasurer by the first day of...