Ohio Revised Code Search

...d proceedings and all bids submitted, unless the time for awarding and executing the contract is extended by mutual consent of the owner or its representatives and the bidder whose bid the owner accepts and with respect to whom the owner subsequently awards and executes a contract. The public owners referred to in this section shall include, in the plans and specifications for the project for which bids are solicited...

... labor performed and material furnished under the contract, with the amount due for each kind of labor and material and the materials and amount due in the aggregate, which estimate shall be based upon actual measurement of such labor and materials, and shall give the amounts of the preceding estimate, and the amount of labor performed and materials furnished since the last estimate. When the major portion of the pro...

... contract, of material delivered on the site of the work, or a railroad station, siding, or other point in the vicinity of the work, or other approved storage site, provided such materials have been inspected and found to meet the specifications. The balance of such invoiced value shall be paid when such material is incorporated into and becomes a part of such building, construction, addition, improvement, alteration...

... hazard evaluation specialist certified under Chapter 3710. of the Revised Code shall assess the hazard and determine appropriate response actions. Enclosure or encapsulation, rather than removal, shall be implemented if the asbestos hazard evaluation specialist determines that both of the following apply: (1) Enclosure or encapsulation would be an appropriate response action; (2) The cost of encapsulating or enclo...

...ate or any institution supported in whole or in part by the state enters into for any project subject to sections 153.01 to 153.11 of the Revised Code. (B) Notwithstanding any contract provision to the contrary, any claim submitted under a public works contract that the state or any institution supported in whole or in part by the state enters into for any project subject to sections 153.01 to 153.11 of the ...

... completion of the project shall be deposited in the original fund from which the capital appropriation for the project was made. The executive director, without controlling board approval, may authorize specified additional uses for the moneys related to completion of the project and may increase the appropriation authority in the appropriation line item used to fund the project by an amount equal to the moneys rece...

...rector of budget and management. The amount so paid shall be charged against the contractor and be deducted from his next or any subsequent estimate. The amount or any part thereof not so paid may be recovered by action from such contractor and his sureties.

...ision in regard to the time when the whole or any specified portion of work contemplated therein shall be completed and that for each day it shall be delayed beyond the time so named the contractor shall forfeit to the state a sum to be fixed in the contract, which shall be deducted from any payment due or to become due to the contractor.

...The attorney general shall have charge of and direct the proceedings necessary to enforce contracts authorized by sections 153.01 to 153.19, inclusive, of the Revised Code.

...lding, the board may appoint four suitable and competent freehold electors of the county, who shall, together with the board, constitute a building commission and serve until the courthouse or other county building, or the addition thereto, or the improvements thereof are completed. Not more than two of such appointees shall be of the same political party.

...2, 1951, shall receive a reasonable compensation for the time actually employed, to be fixed by the court of common pleas and on its approval paid from the county treasury. Their compensation in the aggregate shall not exceed eight thousand dollars.

...correspondence, and travel out of the county required in the discharge of the duties of the building commission shall be paid from the county treasury on the order of the board of county commissioners and the warrant of the county auditor.

...ed by the judge of the court of common pleas. Such bond shall be delivered to the county treasurer and kept in the treasurer's office.

... the vacancy shall be filled by appointment by the judge of the court of common pleas as provided in section 153.21 of the Revised Code.

...rage thereof. Until the building is completed and accepted by the commission, the commission may determine all questions connected therewith. The commission shall be governed by sections 153.01 to 153.60, inclusive, of the Revised Code, relating to the erection of public buildings of the county.

...construction of a courthouse or other county building and fix their compensation and bond.

...of cost thereof shall be filed by the county auditor in his office and shall not be altered, unless such alteration is first drawn, specified, and estimated as required by law for the original plans and approved by the commission. No such change shall be made until the price to be paid therefor has been agreed upon in writing between the commission and the contractor.

...corded on the journal of the board of county commissioners. When signed by five members of the commission, the county auditor shall draw his warrant on the county treasurer for the payment of all bills and estimates of such commission.

...n his office all plans, drawings, representations, bills of material, specifications of work, and estimates of costs in detail and in the aggregate pertaining to the building.

...ials required, with working plans suitable for the use of mechanics or other builders in the construction thereof, drawn so as to be easily understood; (2) Accurate bills, showing the exact amount of the different kinds of material, necessary for the construction, to accompany the plans; (3) Full and complete specifications of the work to be performed showing the manner and style required to be done, with such di...

...ructing a public building in stages and letting contracts from time to time for various portions of the work, so long as the total cost of construction of a project, which may include more than one building, is reasonably estimated by the board to exceed fifteen million dollars.

...ounty commissioners shall determine the length and width of the superstructure, and whether it shall be single or double track, and it shall advertise for bids for performing the labor and furnishing the materials necessary to the erection thereof in accordance with sections 307.86 to 307.92 of the Revised Code.

...the county auditor for a period of fifteen days prior to the date for receiving bids. Such plans and specifications shall show the number of spans, the length of each, the nature, quality, and size of the materials to be used, the length of the structure when completed, and whether there is any patent on the bid plan, or any part thereof, and if so, on what part thereof.

...In its advertisement, the board of county commissioners shall invite bidders to make bids for furnishing all the materials and performing all the work, or for such parts thereof as bidders deem proper, and include such other matter as is required in section 307.87 of the Revised Code.

... contract with the successful bidder. When it is necessary to alter, repair, or make an addition to a bridge, the board of county commissioners in making contracts therefor, shall conform to sections 153.01 to 153.60, inclusive, of the Revised Code, in relation to the erection of bridges as nearly as the nature of the case will permit.