Ohio Revised Code Search

...(A) As used in this section: (1) "Costs of sites and facilities" includes related direct administrative expenses and allocable portions of the direct costs of those projects. "Costs of sites and facilities" includes "allowable costs" as defined in section 122.085 of the Revised Code. (2) "Obligations" means obligations as defined in section 151.01 of the Revised Code issued to pay costs of sites and faciliti...

...(A) As used in this section: (1) "Bond proceedings" includes any trust agreements, and any amendments or supplements to them, as authorized by this section. (2) "Costs of revitalization projects" includes related direct administrative expenses and allocable portions of the direct costs of those projects of the department of development or the environmental protection agency. (3) "Issuing authority" means the...

...in part by the state or in or upon the public works of the state that is administered by the Ohio facilities construction commission or by any other state officer or state agency authorized by law to administer a project, including an educational institution listed in section 3345.50 of the Revised Code, is to be erected or constructed, whenever additions, alterations, or structural or other improvements are t...

...teel products for use in contracts for public bridge projects. The executive director of the Ohio facilities construction commission may waive the requirements of division (A) of this section if the executive director determines that either division (A) or (B) of section 5525.21 of the Revised Code is true in connection with a public bridge project. The executive director shall issue this determination in writ...

...on, repair, painting or decoration of a public improvement, including any highway improvement, made by the state or in whole or in part supported by the state, except for a contract for products produced or mined in Ohio or for a contract financed in whole or in part by contributions or loans from any agency of the United States government, preference shall be given to contractors having their principle place of busi...

...(A) As used in this section, "indefinite delivery indefinite quantity contract" means a contract for an indefinite quantity, within stated limits, of supplies or services that will be delivered by the awarded bidder over a defined contract period. (B) The executive director of the capitol square review and advisory board, with the approval of the board, may advertise and seek bids for, and may award, an indefinite ...

...r a contractor from contract awards for public improvements as referred to in section 153.01 of the Revised Code or for projects as defined in section 3318.01 of the Revised Code, upon proof that the contractor has done any of the following: (1) Defaulted on a contract requiring the execution of a takeover agreement as set forth in division (B) of section 153.17 of the Revised Code; (2) Knowingly failed during th...

...mentality that is authorized to award a public improvement contract. (2) "Bidder" means a person who submits a bid to a contracting authority to perform work under a public improvement contract. (3) "Contractor" means any person with whom a contracting authority has entered into a public improvement contract to provide labor for a public improvement and includes a construction manager at risk and a design-bui...

...constructing, altering, or repairing of public improvements of the state and to be of assistance in ensuring that such public improvements are constructed, altered, or repaired in a manner that protects the safety of the citizens of this state.

...The plans, details, bills of material, specifications of work, estimates of cost in detail and in the aggregate, life-cycle cost analysis, form of bid, bid guaranty, and other data that may be required shall be prepared on such material and in such manner and form as are prescribed by the Ohio facilities construction commission. The life-cycle costs shall be a primary consideration in the selection of a design....

...The bond required by section 153.08 of the Revised Code may be enforced against the person executing such bond, by any claimant for labor or material, and suit may be brought on such bond in the name of the state on relation of the claimant within one year from the date of delivering or furnishing such labor or material, in the court of common pleas of the county wherein such labor or material was furnished or delive...

... 153.01 of the Revised Code shall give public notice of the time and place when and where bids will be received for performing the labor and furnishing the materials of such construction, improvement, alteration, addition, or installation, and a contract awarded, except for materials manufactured by the state or labor supplied by a county department of job and family services that may enter into the same. The f...

...ties construction commission, the last publication to be at least eight days preceding the day for opening the bids, and in such form and with such phraseology as the commission orders. Copies of the plans, details, estimates of cost, and specifications shall be open to public inspection at all business hours between the day of the first publication and the day for opening the bids, at the office of the commis...

...ised Code shall open the bids and shall publicly, with the assistance of the architect or engineer, immediately proceed to tabulate the bids. For a bid filed electronically, the public bid opening may be broadcast by electronic means pursuant to rules established by the Ohio facilities construction commission. A bid shall be invalid and not considered unless a bid guaranty meeting the requirements of section 153.54 o...

...If in the opinion of the owner referred to in section 153.01 of the Revised Code, the award of a contract to the lowest responsive and responsible bidder is not in the best interests of the state, the owner may accept another bid so opened or reject all bids, and advertise for other bids. Such advertisement shall be for such time, in such form, and in such newspaper as the Ohio facilities construction commissio...

...After the plans, bills of material, specifications of work, estimates of cost in detail and in the aggregate, life-cycle cost analysis, form of bid, bid guaranty, and other data that may be required are approved and filed with the owner as defined in section 153.01 of the Revised Code, no change of plans, details, bills of material, or specifications shall be made or allowed unless the same are approved by the owner ...

...Whenever the change referred to in section 153.10 of the Revised Code is approved by the owner as defined in section 153.01 of the Revised Code, accepted in writing by the contractor, and filed, the same shall be considered as being a part of the original contract, and the bond theretofore executed shall be increased or decreased accordingly to include and cover the change in the contract.

...n, repair, painting, or decoration of a public improvement made by the state, or any county, township, municipal corporation, school district, or other political subdivision, or any public board, commission, authority, instrumentality, or special purpose district of or in the state or a political subdivision or that is authorized by state law, the award, and execution of the contract, shall be made within sixty days ...

...At the time named in the contract for payment to the person with whom it is made, the owner referred to in section 153.01 or 153.12 of the Revised Code shall approve a full, accurate, and detailed estimate of the various kinds of labor performed and material furnished under the contract, with the amount due for each kind of labor and material and the materials and amount due in the aggregate, which estimate shall be ...

...n of those projects, improvements, and public buildings over which the Ohio facilities construction commission has general supervision pursuant to section 123.21 of the Revised Code, the estimates referred to in section 153.13 of the Revised Code shall be filed with the executive director by the owner referred to in section 153.01 or 153.12 of the Revised Code. Upon completion of a project referred to in secti...

...(A) Whenever an asbestos hazard abatement activity is being performed in a building or structure supported in whole or in part by the state, an asbestos hazard evaluation specialist certified under Chapter 3710. of the Revised Code shall assess the hazard and determine appropriate response actions. Enclosure or encapsulation, rather than removal, shall be implemented if the asbestos hazard evaluation specialist deter...

...conjunction with the administration of public works contracts that the state or any institution supported in whole or in part by the state enters into for any project subject to sections 153.01 to 153.11 of the Revised Code. (B) Notwithstanding any contract provision to the contrary, any claim submitted under a public works contract that the state or any institution supported in whole or in part by the state ...

...(A) When in the opinion of the owner referred to in section 153.01 of the Revised Code, the work under any contract made under any law of the state is neglected by the contractor or such work is not prosecuted with the diligence and force specified or intended in the contract, such owner may make requisition upon the contractor for such additional specific force or materials to be brought into the work under such con...

...The owner referred to in section 153.01 of the Revised Code shall make separate estimates of all additional force or materials employed or supplied as provided by section 153.17 of the Revised Code, and payment shall be provided for by the director of budget and management. The amount so paid shall be charged against the contractor and be deducted from his next or any subsequent estimate. The amount or any part there...

...All contracts under sections 153.01 to 153.60, inclusive, of the Revised Code, shall contain provision in regard to the time when the whole or any specified portion of work contemplated therein shall be completed and that for each day it shall be delayed beyond the time so named the contractor shall forfeit to the state a sum to be fixed in the contract, which shall be deducted from any payment due or to become due t...